1. Agreement to These Terms
By browsing this website or purchasing products from Projectway LTD, you acknowledge that you have read, understood, and accepted these Terms of Website Use & Sale. If you do not agree with any part of these terms, please discontinue use of this website immediately.
2. Company Information
Projectway LTD is a UK-based supplier of construction and building materials. Throughout these terms, “Company”, “we”, “our”, and “us” refer to Projectway LTD, while “customer”, “buyer”, and “you” refer to any individual or business using this website.
Registered Address:
11 Crabtree
Peterborough
England
PE4 7EG
United Kingdom
3. Product Details
Every effort is made to provide accurate descriptions, images, and specifications for our products. However, slight differences in colour, finish, packaging, or dimensions may occur due to manufacturing improvements or photographic lighting.
4. Availability of Goods
All items displayed on our website are subject to stock availability. We reserve the right to withdraw, replace, or discontinue products at any time without prior notice.
5. Order Confirmation
Submitting an order does not automatically create a binding contract. Orders become legally accepted only after payment has been authorised and we issue an order confirmation.
6. Prices & Charges
All prices shown are in Pound Sterling (GBP). Taxes and delivery charges will be applied where applicable and clearly displayed before checkout. We reserve the right to amend prices without prior notice.
7. Accepted Payment Methods
Payment must be completed using one of the approved payment methods available during checkout. Orders may be delayed or cancelled if payment cannot be successfully verified.
8. Shipping & Dispatch
Delivery estimates are provided for guidance only and should not be considered guaranteed delivery dates. Delivery schedules may change due to courier delays, supplier shortages, weather conditions, or other circumstances beyond our reasonable control.
9. Delivery Inspection
Customers should examine all goods immediately upon delivery. If products arrive damaged, incomplete, or incorrect, notification should be provided within 48 hours so that appropriate action can be taken.
10. Returns & Exchanges
Products may be returned only if they remain unused, undamaged, and in their original packaging. Custom-built, special-order, or personalised products cannot normally be returned unless they are faulty or incorrectly supplied.
11. Product Warranty
Where applicable, products are covered by the manufacturer’s warranty. The warranty does not apply to damage resulting from incorrect installation, misuse, negligence, accidental damage, or normal wear and tear.
12. Customer Obligations
Customers agree to provide accurate order information, ensure suitable access for deliveries, follow installation guidance where applicable, and use purchased products safely and responsibly.
13. Ownership of Website Content
All website content, including photographs, graphics, logos, product descriptions, designs, text, and branding, remains the intellectual property of Projectway LTD. No material may be copied, reproduced, distributed, or published without our prior written permission.
14. Acceptable Website Behaviour
Visitors must not attempt to interfere with the operation or security of this website. Activities including hacking, introducing malicious software, scraping data, or using the website for unlawful purposes are strictly prohibited.
15. Privacy & Personal Information
Any personal information collected through this website will be processed responsibly and in accordance with our Privacy Policy and applicable UK data protection legislation.
16. Events Beyond Our Control
Projectway LTD shall not be held responsible for delays or failure to perform obligations caused by circumstances beyond our reasonable control, including natural disasters, transport disruption, supplier issues, industrial action, or government restrictions.
17. Liability Disclaimer
To the fullest extent permitted by law, Projectway LTD shall not be responsible for indirect, incidental, or consequential losses arising from the use of our website or products. Our total liability shall never exceed the value of the relevant order.
18. Changes to These Terms
We reserve the right to revise or update these Terms of Website Use & Sale whenever necessary. Any amendments will become effective immediately after publication on this website.
19. Applicable Law
These Terms of Website Use & Sale shall be governed by the laws of England and Wales. Any legal dispute shall fall under the exclusive jurisdiction of the courts of England and Wales.